Terms and Conditions

Introduction

These Terms and Conditions govern the use of services provided by Kraft Construction LLC. By engaging with our luxury home construction or custom horse barn projects, you agree to comply with the following terms.

Scope of Services

Kraft Construction LLC specializes in high-end residential construction and custom horse barns. Services include, but are not limited to, design consultation, project management, construction, and post-construction support.

Project Agreements

All project details, including timelines, costs, and deliverables, will be agreed upon in a formal contract. Any modifications to the scope or timeline will require written approval from both parties.

Payments

Payment terms will be outlined in the project agreement. Clients are responsible for timely payments as per the agreed schedule. Failure to comply with payment terms may result in delays or suspension of services.

Client Responsibilities

Clients are expected to provide accurate information and necessary permissions for the project to proceed. Delays due to lack of access or failure to provide required details will affect project timelines.

Subcontractors and Suppliers

We may engage subcontractors and suppliers to complete certain aspects of the project. Kraft Construction LLC ensures that all subcontractors meet our standards of quality and professionalism.

Liability

Kraft Construction LLC is not liable for delays or issues arising from factors beyond our control, including weather, third-party delays, or unforeseen circumstances. We are committed to resolving any issues within the scope of our agreement.

Governing Law

These terms shall be governed by the laws of [State]. Any disputes arising from our services will be resolved in the courts of [State].

Changes to Terms and Conditions

We reserve the right to update these Terms and Conditions as needed. Clients will be notified of any significant changes before they take effect.